Summary: — **Background & Objective** – NTPC filed a petition under **Section 63 of the Electricity Act, 2003** for adoption of tariffs discovered through a **competitive bidding process**. – The tender was for procurement of **760 MW** of **Firm and Dispatchable Power (Assured Peak Power Supply)** from **ISTS-connected renewable energy projects with energy storage systems**. […]
Policy & Regulation
In the Matter of Approval the CERC (Conduct of Business) and (Terms and Conditions of Tariff) Regulations under System Strengthening Scheme in Northern Region–XXXVII (NRSS-XXXVII) – EQ
Summary: — **Key Dates & Delays** – **Asset-1:** SCOD – 19.12.2019, COD – 4.12.2022 → **Time overrun: 1081 days** – **Asset-2:** COD claimed as 5.1.2023 → Delay due to unready downstream asset by PTCUL. – **Asset-3:** COD claimed as 5.1.2023 → Delay due to washed-out bridge preventing reactor relocation. **PGCIL’s Claims** – **Asset-2:** COD claimed […]
In the matter of Approval the CERC (Conduct of Business) and (Terms and Conditions of Tariff) Regulations for determination of transmission tariff from COD under TSA with Mundra Ultra Mega Power Project – EQ
Summary: — # **1. Scope of Work** The bidder must execute the *complete* EPC + long-term O&M responsibility for: ### **🔹 10 MW Rooftop Solar PV System (Jodhpur District)** * Installation on multiple State Government office buildings, institutional buildings, and other public structures. * Project includes design, engineering, supply, installation, net-metering, commissioning, and maintenance for […]
Petition for Truing up and determination of the transmission tariff of the CERC (Conduct of Business) ans (Terms and Conditions of Tariff) Regulations for Phase-II generation projects in Odisha” in the Eastern region – EQ
Summary: — ## **1. Nature of the Petition** The petition has been filed by **Power Grid Corporation of India Limited (PGCIL)** seeking: 1. **Truing-up** of transmission tariff for the period **2019–24**. 2. **Determination of tariff** for the next control period **2024–29**. The assets involved belong to the **“Common Transmission System for Phase-II Generation Projects in […]
Petition for Truing up and determination of transmission tariff under Western Region System Strengthening Scheme (XVIII) in the Western Region – EQ
Summary: — ### **List of Petitions Covered** | Petition No. | Subject / Scheme | Region | Main Respondent | |————-|——————|——–|—————-| | 403/TT/2025 | Western Region System Strengthening Scheme (XVIII) | Western | MPPMCL + 6 others | | 544/TT/2025 | Transmission System Strengthening in Wardha-Aurangabad Corridor for IPP projects in Chhattisgarh (IPP-G) | Western […]
Petition for determination of transmission tariff under the transmission system associated with the “North East Northern/Western Interconnector-I Project” in the North-Eastern Region – EQ
Summary: — **Case Details** – **Petition No:** 211/TT/2024 – **Subject:** Determination of transmission tariff from COD/Proposed COD/Anticipated COD to 31.03.2024 for **4 transmission assets** under the *North East Northern/Western Interconnector-I Project* in the North-Eastern Region – **Petitioner:** PGCIL – **Respondents:** Assam Power Distribution Company Limited (APDCL) and 8 others – **Date of Hearing:** 27.11.2025 – […]
Petition for determination of transmission tariff from the COD to System Strengthening Scheme in the Northern Region–XXXVII (NRSS-XXXVII) – EQ
Summary: — **Case Details** – **Petition No:** 330/TT/2023 – **Subject:** Determination of transmission tariff from the Commercial Operation Date (COD) to 31.03.2024 for three assets under the *System Strengthening Scheme in the Northern Region–XXXXII (NRSS-XXXVII)* – **Petitioner:** Power Grid Corporation of India Limited (PGCIL) – **Respondents:** Power Transmission Corporation of Uttarakhand Limited (PTCUL) and 15 […]
Petition for the determination of transmission tariff under Transmission System strengthening scheme for evacuation of power from solar energy zones in Rajasthan (8.1GW) under Phase-II-Part F1 – EQ
Summary: —- **Subject of Petition:** Power Grid Corporation of India Limited (PGCIL) has filed a petition for **determination of transmission tariff** from the Date of Commercial Operation (DOCO) until **31 March 2024** for specific transmission assets under a **renewable energy evacuation scheme** in Rajasthan. **Assets Involved:** – **Substation:** 400kV Bikaner-II Pooling Station (PS) – extension […]
Petition for Truing up and for the determination of transmission tariff for Uravakonda-Veltoor, Kamavarapukota-Suryapet I & II lines for tariff period – EQ
Summary: —- **Key Entities:** – **Petitioner:** APTRANSCO (Transmission Corporation of Andhra Pradesh Limited) – **Respondents:** Transmission Corporation of Telangana Limited (TSTRANSCO) and another (likely CTUIL – Central Transmission Utility of India Ltd.) – **CTUIL** was present at the hearing as Respondent No. 2. **Date of Hearing:** 20 November 2025 **Proceedings Summary:** 1. The petitioner’s counsel […]
In the matter of DRAFT Sixth amendment to MPERC (Terms and Conditions for Intra-State Open Access in Madhya Pradesh) (Revision-I) Regulations – EQ
In the matter of DRAFT Sixth amendment to MPERC (Terms and Conditions for Intra-State Open Access in Madhya Pradesh) (Revision-I) Regulations For more information please see below link: