Summary: —- #### 1. Core Dispute: Delay in Project Commissioning – **The Project:** A 4.00 MW (3.90 MW AC) solar power project under the **captive use category**. – **Petitioner’s Argument for Delay:** The developer blamed the utilities for delays in signing the connection agreement and providing estimates for supervision charges. They claimed the agreement was […]
Petition of GERC (Conduct of Business) Regulations for commissioning of 4 MW AC Solar Power Project at District- Bharuch – EQ
Summary: — ## **Gujarat Electricity Regulatory Commission (GERC) – Daily Order** ### 📌 Case Details * **Petition No.:** 2479 of 2025 * **Petitioner:** *M/s. Shree Ganesh Enterprise* (Proprietor: Mr. Jaydip M. Patel) * **Respondents:** 1. Gujarat Energy Transmission Corporation Ltd. (GETCO) 2. Gujarat Urja Vikas Nigam Ltd. (GUVNL) 3. Dakshin Gujarat Vij Company Ltd. (DGVCL) […]