Summary: —- **1. Overview of the Petition** – **Petitioner:** Power Grid Corporation of India Limited (PGCIL). – **Purpose:** 1. **Truing-up** of Annual Fixed Charges (AFC) for the 2019-24 tariff period (based on 2019 Tariff Regulations). 2. **Determination** of AFC for the 2024-29 tariff period (based on 2024 Tariff Regulations). – **Asset in Question (Combined Asset):** […]
Petition for Truing up and determination of transmission tariff of the CERC (Conduct of Business) and (Terms and Conditions of Tariff) Regulations for DTL – EQ
Summary: —- ### Key Procedural Developments #### 1. **Compliance Status** – The counsel for DTL informed the Commission that the additional information requested by CERC in its previous order (RoP dated 20.11.2025) had been submitted via an affidavit dated January 8, 2026. – DTL also requested permission to file comprehensive **Written Submissions** to consolidate their […]
Petition for Truing up and determination of transmission tariff of the CERC (Conduct of Business) and (Terms and Conditions of Tariff) Regulations for SPTL – EQ
Summary: —- ### Key Directives and Information Required from SPTL #### 1. **Compliance and Procedural Directives** – **Amended Petition:** SPTL must file an amended petition aligning with a consequential order dated 29.12.2025 in Petition No. 108/TT/2016, which itself was based on an APTEL judgment dated 25.3.2025. – **Notice to Respondents:** After filing the amended petition, […]
Petition of GERC (Conduct of Business) Regulations and Gujarat Renewable Energy Policy for commissioning of 4 MW AC Solar Power Project at Village – Dungri, Taluka-Valia District Bharuch – EQ
Summary: —- #### 1. Core Dispute: Delay in Project Commissioning – **The Project:** A 4.00 MW (3.90 MW AC) solar power project under the **captive use category**. – **Petitioner’s Argument for Delay:** The developer blamed the utilities for delays in signing the connection agreement and providing estimates for supervision charges. They claimed the agreement was […]
In the matter of the CERC (Conduct of Business) and (Terms and Condition of Tariff) Regulations for truing up and determination for Vindhayachal Pooling- Varanasi Line” under POWERGRID works associated with Inter Regional Corridor – EQ
Summary: —- #### 1. The Dispute and Legal Context – **Petitioner:** NTPC Ltd., India’s largest energy conglomerate. – **Respondents:** A group of 26 electricity distribution companies, including APEPDCL (Andhra Pradesh), MPPMCL (Madhya Pradesh), NBPDCL & SBPDCL (Bihar), and MSEDCL (Maharashtra). – **Legal Basis:** The case is being heard under the CERC (Terms & Conditions of […]
In the matter of CERC (Conduct of Business) and (Terms and Conditions of Tariff) Regulations for truing up and the determination for “Transmission System for controlling high Short Circuit” in the Southern Region – EQ
Summary: —- #### Key Details: – **Petitioner:** Power Grid Corporation of India Limited (PGCIL). – **Regulatory Authority:** Central Electricity Regulatory Commission (CERC), New Delhi. – **Date of Order:** 26th February 2026. – **Project Name:** Transmission System for controlling high Short Circuit Current level at 400 kV Thiruvalam S/s (Southern Region). – **Asset Details:** – **Asset-1:** […]
In the matter of the CERC (Conduct of Business) and (Terms and Conditions of Tariff) Regulations for the Combined Asset under “System Strengthening – XXVI” in the Southern Region – EQ
Summary: —– #### Key Details: – **Petitioner:** Power Grid Corporation of India Limited (PGCIL). – **Regulatory Authority:** Central Electricity Regulatory Commission (CERC), New Delhi. – **Date of Order:** 24th February 2026. – **Project Name:** System Strengthening – XXVI (Southern Region). – **Assets Involved:** – **Asset-1:** 2 x 220 kV line bays at Cochin East Substation […]
In the matter of the CERC (Conduct of Business) and (Terms and Condition of Tariff) for truing up and determination of transmission tariff for Baharampur (POWERGRID) – Bheramara (BANGLADESH) in the Eastern Region – EQ
Summary: — ### Detailed Analysis of the CERC Order #### 1. Background and Project Overview – **Petitioner:** Power Grid Corporation of India Limited (PGCIL), the Central Transmission Utility. – **Respondent:** Bangladesh Power Development Board (BPDB), the sole beneficiary of the transmission asset. – **Asset in Question:** 400kV D/C (02nd) Baharampur (POWERGRID) – Bheramara (BANGLADESH) transmission […]
In the matter of the CERC (Conduct of Business) and (Terms and Conditions of Tariff) Regulations for the Combined Asset under “Eastern Region Strengthening scheme-XI” in the Eastern Region – EQ
Summary: —- ### Key Details of the Tender – **Estimated Cost of Work:** **Rs 40.50 Lakhs** (At par Market) – **Period of Completion:** **180 days** – **Cost of Tender Documents:** **Rs 500.00** (Payable via DD/Banker’s Cheque in favor of GE (FW) Kolkata). *Note: Contractors who bid in the previous tender are exempt from this cost.* […]
In the matter of the CERC (Conduct of Business) and (Terms and Conditions of Tariff) Regulations for implementation of Kurnool (New) Sub-station in the Southern Region – EQ
Summary: —- **Objective:** This is an item-rate e-tender for the Annual Maintenance Contract (AMC) of a 730 KWp ground-mounted solar power plant and Comprehensive Maintenance Contract (CMC) of its inverters at Madurai Airport for a three-year period (2025-2028). **Key Business Implications for Bidders (Service Contractors):** 1. **Specialized Service Opportunity:** The contract is specifically for Operation […]