Summary: —- **Key Legal & Procedural Developments:** 1. **Compliance with Previous Orders:** ATL informed the Commission that it has complied with directions issued on January 21, 2026, by: – Impleading **KPS III HVDC Transmission Limited** as a co-petitioner. – Adding **Powergrid KPS3 Transmission Limited** and **South Olpad Transmission Limited** as respondents. 2. **Stakeholder Objections:** ATL […]
Petition for Truing up and determination of transmission tariff of the CERC (Conduct of Business) and (Terms and Conditions of Tariff) Regulations for DTL – EQ
Summary: —- ### Key Procedural Developments #### 1. **Compliance Status** – The counsel for DTL informed the Commission that the additional information requested by CERC in its previous order (RoP dated 20.11.2025) had been submitted via an affidavit dated January 8, 2026. – DTL also requested permission to file comprehensive **Written Submissions** to consolidate their […]
Petition for Truing up and determination of transmission tariff of the CERC (Conduct of Business) and (Terms and Conditions of Tariff) Regulations for SPTL – EQ
Summary: —- ### Key Directives and Information Required from SPTL #### 1. **Compliance and Procedural Directives** – **Amended Petition:** SPTL must file an amended petition aligning with a consequential order dated 29.12.2025 in Petition No. 108/TT/2016, which itself was based on an APTEL judgment dated 25.3.2025. – **Notice to Respondents:** After filing the amended petition, […]
Petition for extension of date of grid connectivity and commissioning of 7.8 MW Solar Plant for captive use due to occurnance of uncontrollable events – EQ
Summary: —- #### 1. Core Dispute: Extension Due to “Uncontrollable Events” – **The Petition:** Filed under **Section 86 (1) (c), (e), and (f)** of the Electricity Act, 2003, and Clause 3.9 of GERC Order No. 06 of 2024. – **Relief Sought:** Extension of the date for **grid connectivity and commissioning** for a 7.8 MW solar […]
Petition of GERC (Conduct of Business) Regulations and Gujarat Renewable Energy Policy for commissioning of 4 MW AC Solar Power Project at Village – Dungri, Taluka-Valia District Bharuch – EQ
Summary: —- #### 1. Core Dispute: Delay in Project Commissioning – **The Project:** A 4.00 MW (3.90 MW AC) solar power project under the **captive use category**. – **Petitioner’s Argument for Delay:** The developer blamed the utilities for delays in signing the connection agreement and providing estimates for supervision charges. They claimed the agreement was […]
Draft GERC (Terms and Conditions for Green Energy Open Access) (Fourth Amendment) Regulations, 2026 – EQ
Summary: —- #### 1. Core Objective of the Amendment – **What it is:** The amendment modifies Regulation 17.6 (viii) of the principal GEOA Regulations, 2024, which deals with “Banking facility and Charges.” – **The Change:** It introduces a specific, fixed **banking charge of ₹1.50 per unit**. – **Business Implication:** Banking allows a generator (like a […]
Petition of the CERC (Terms and Conditions of Tariff) and (Terms and Conditions of Tariff) Regulations for truing-up and determination of tariff of Srinagar PH Line (Deemed ISTS) – EQ
Summary: —- #### 1. Case Background and Legal Context – **Petitioner:** Power Transmission Corporation of Uttarakhand Limited (PTCUL), the state transmission utility. – **Respondents:** Power Grid Corporation of India Limited (PGCIL) and other stakeholders. – **Subject Asset:** The petition concerns the **400 kV Srinagar – Srinagar PH Transmission Line**, which is part of the “UITP […]
In the matter of the CERC (Conduct of Business) and (Terms and Condition of Tariff) Regulations for truing up and determination for Vindhayachal Pooling- Varanasi Line” under POWERGRID works associated with Inter Regional Corridor – EQ
Summary: —- #### 1. The Dispute and Legal Context – **Petitioner:** NTPC Ltd., India’s largest energy conglomerate. – **Respondents:** A group of 26 electricity distribution companies, including APEPDCL (Andhra Pradesh), MPPMCL (Madhya Pradesh), NBPDCL & SBPDCL (Bihar), and MSEDCL (Maharashtra). – **Legal Basis:** The case is being heard under the CERC (Terms & Conditions of […]
Petition of the CERC (Terms & Conditions of Tariff) Regulations with NTPC Ltd. – EQ
Summary: —- The core issue involves tariff regulations under the CERC (Terms & Conditions of Tariff) Regulations, 2019. #### Key Outcomes of the Hearing: 1. **Adjournment Request:** The legal counsel for the Bihar Discoms (respondents) requested an adjournment, citing the unavailability of their main arguing counsel. Counsel for MSEDCL also sought additional time to file […]
Petition with CERC (Procedure, Terms and Conditions for Grant of Transmission License and other related matters) Regulations for Transmission system with RE applicant(s) at Navinal (Mundra)(GIS) – EQ
Summary: — ### 1. Overview of the Hearing This document is a “Record of Proceedings” from a CERC hearing regarding the grant of a transmission license. Navinal Transmission Limited (NNTL) is seeking a license to build a transmission system to connect Renewable Energy (RE) applicants at Navinal (Mundra) in Gujarat. The project is proposed under […]